Terms and Conditions of Service for Renewable Energy Products and Services
Last Updated: 01/01/2024
1. Definitions
- “Robin Renewables Ltd” refers to the service provider.
- “Client” refers to the party entering into a contract for renewable energy products or services with Robin Renewables Ltd.
- “Services” refer to any renewable energy-related products, installation, maintenance, or consulting services provided by Robin Renewables Ltd.
- “Products” refer to any renewable energy equipment or technology supplied by Robin Renewables Ltd.
- “Contract” refers to the agreement between Robin Renewables Ltd and the Client for the provision of Renewable Energy Products and Services.
2. Acceptance of Terms
By engaging in business with Robin Renewables Ltd, the Client acknowledges and agrees to be bound by these terms and conditions, which constitute the entire agreement between the parties. Any additional terms or conditions proposed by the Client are expressly rejected unless agreed upon in writing by both parties.
3. Scope of Services
Robin Renewables Ltd agrees to provide the Services to the Client as specified in the contract. The scope of Services may include, but is not limited to, the design, supply, installation, and maintenance of renewable energy systems.
4. Pricing and Payment
The Client shall pay for the Services and Products in accordance with the pricing and payment terms specified in the contract. All fees and charges are subject to applicable taxes and will be invoiced accordingly. Payment terms and milestones will be outlined in the contract.
5. Warranties and Guarantees
Robin Renewables Ltd shall provide warranties and guarantees for its Products and Services as specified in the contract. Any claims under these warranties or guarantees shall be subject to the terms and conditions outlined therein.
6. Liability
Robin Renewables Ltd shall not be liable for any direct, indirect, consequential, or incidental damages arising out of the provision of Services, including but not limited to, loss of profits, loss of data, or business interruption.
7. Termination
Either party may terminate the contract with written notice if the other party breaches any material term or condition of the contract. In such cases, any outstanding fees or charges shall become immediately due.
8. Returns Policy
8.1 Within 21 days of the receipt of Products, the Client may request to return the goods for a refund. The Client is responsible for covering the carriage charges associated with the return.
8.2 Returned Products must be in their original condition and packaging. Robin Renewables Ltd reserves the right to inspect the returned goods and may deduct any applicable damages or restocking fees from the refund. A restocking fee of up to 5% may be applied to returns.
9. Force Majeure
Robin Renewables Ltd shall not be liable for any delay or failure in the performance of its obligations under the contract due to circumstances beyond its reasonable control, including but not limited to acts of nature, government regulations, or acts of terrorism.
10. Confidentiality
Both parties agree to keep all confidential information obtained during the course of the contract confidential and not disclose it to third parties, except as required by law.
11. Governing Law and Jurisdiction
The contract shall be governed by and construed in accordance with the laws of England and Wales, and any disputes shall be subject to the exclusive jurisdiction of the courts of England and Wales.
12. Environmental Impact
Robin Renewables Ltd is committed to environmental responsibility. The Client acknowledges that renewable energy projects may have environmental impacts and agrees to comply with all relevant environmental laws and regulations.
13. Health and Safety
The Client is responsible for ensuring the safety of its employees, contractors, and the public during the installation and operation of renewable energy systems.
14. Data Protection
Robin Renewables Ltd may collect and process personal data as necessary for the provision of Services, in compliance with applicable data protection laws. The Client consents to such data processing.
15. Changes to the Contract
Any changes or amendments to the contract must be made in writing and signed by both parties.